JBCC Contract Template fot Minor Works JBCC Minor Works Contract Doc. October 10, | Author: Sarisha Harrychund | Category: General Contractor. JBCC Minor Works Agreement. Edition: Year Published: March Author: The Joint Building Contracts Committee Publisher: The Joint Building. JBCC Minor Works Agreement Contract Data Edition: Year Published: Publisher: Joint Building Contracts Committee Price: R Incl.
|Published (Last):||21 December 2010|
|PDF File Size:||17.44 Mb|
|ePub File Size:||7.43 Mb|
|Price:||Free* [*Free Regsitration Required]|
The document drawn up according to the measuring system as stated in the contract data. Where the final account: Where applicable such amount shall M inor W orks Agreement Page 4 include existing buildings and their contents.
The construction period and imnor defects liability period shall commence with the handover of the site 5. The contractor shall be entitled to additional payment due to a delay caused by: In pursuance of the objective the parties undertake to carry out their reciprocal obligations 1.
The form of guarantee provided by the employer or contractor, as stated in the contract data, from which a party may recover expense and loss in the event of jbcf SITE: Where considered necessary the principal agent shall revise the kbcc account within ten 10 working days and resubmit such final account to the contractor The contractor shall report the cause and effect of such delay and the working days claimed to the principal agent at the next meeting held [6.
Failure to agree the value shall not relieve the contractor of his responsibility to comply with the contract instruction ubcc The retention held shall include any unpaid amount due [ The edition of the Summary Procedure Rules for the Conduct of Arbitrations, published by the Association of Arbitrators Southern Africa and current when the dispute is declared, shall apply Such liability shall not exceed the insurance deductible stated in the contract data in any particular instance 4.
JBCC Minor Works Contract Doc
We need your help! Such guarantee shall be issued by a guarantor to the reasonable approval of the employer 2.
Works also includes materials and goods and those supplied free or otherwise by the employer to the contractor and excludes work or installations to be executed by direct contractors 1. The other objectives of the JBCC are to: No agreement or addendum varying, adding to, deleting or terminating this agreement including this clause shall be effective unless reduced to writing and signed by the parties Please copy and paste this embed script to where you want to embed Embed Script.
Such change shall be deemed to be a contract instruction 7.
Should the contractor fail to submit such an analysis the principal agent shall prepare the analysis M inor W orks Agreement Page 16 The ruling bank rate on the first calendar day of each month shall be used in calculating the interest due for such month JBCC: Where the final payment certificate favours the employer the security shall expire when the contractor makes payment The principal agent shall deal with the amounts thus paid [ The contract minutes shall be tabled for approval at the following meeting 6.
A defect that a reasonable inspection of the works by the principal agent would not have revealed before the issue of the defects list LAW: The principal agent shall not preselect any of the alternatives available to the contractor Please fill jbcd form, we will try to respond as soon as possible.
JBCC Minor Works Contract Doc – Free Download PDF
The land or place on, over, under, in or through which the works is to be executed and as stated in the contract monor TAX: Twenty-four 24 hour days commencing at midnight We need your help to maintenance this website.
We are a non-profit group that run this website to share documents. The contractor may appoint a competent representative to administer and control the works in his stead. Either party may, at any time, by notice to the other change, its physical address provided that it is jbcd the same country as that initially stated in the contract data 1.
No part of this publication may be reproduced, stored in any retrieval system, or transmitted, in any form or by any means, electronic, mechanical, photocopying, scanning, recording, or otherwise, without the prior permission of the Joint Building Contracts Committee.
The amount payable by the contractor [ The documentation sets out a clear, balanced and enforceable set of procedures, rights and obligations, which when competently managed and administered, protect the employer and contractor alike.
The bank rate that is applicable from time to time to registered banks when borrowing money from the Central or Reserve Bank of the country named in the contract data.
Materials and goods delivered to the contractor for inclusion in the works stored on the site but not yet part of the works PARTY: Thus done and signed at on Name of signatory Capacity of signatory for and on behalf of the employer who by signature hereof warrants authorisation hereto Worke as Witness 1 Thus done and signed at Name of signatory on for and on behalf of the contractor who by signature hereof warrants authorisation hereto Capacity of signatory Signed as Witness 2 Details of Witness 1 Details of Witness 2 Name: